Digital Artist
Milkzuki's Terms of Service
By commissioning Milkzuki, you agree to the following Terms of Service (TOS). Failure to comply may result in cancellation of your commission and/or blacklisting without a refund.By proceeding with payment, you confirm that you have read and agreed to these Terms of Service.For inquiries or commission requests, please contact Milkzuki directly.
Milkzuki's Terms of Service
General Terms
- The commissioner must read and agree to these Terms of Service before purchasing.- These terms may be updated at any time. It is the commissioner’s responsibility to review them before commissioning.
Milkzuki's Terms of Service
Payment & Pricing
- Payments can be made via Mastercard/Visa transfer, PayPal, or Ko-fi in USD or EUR.- Prices listed in samples are for reference only; final pricing depends on the complexity of the request.- When the commission is accepted, a 50% deposit must be placed to begin the work.- The remaining 50% will be due after the customer’s approval of the sketch before finalizing the artwork.
Milkzuki's Terms of Service
Process & Delivery
- Commissions are completed in the order they are received.- Turnaround time varies depending on complexity and workload; estimated completion time will be discussed before payment.- The commissioner will receive progress updates, including sketches, line art, coloring, shading, and rendering. Any changes will also be updated.- The final artwork will be delivered digitally via email or a designated platform.
Milkzuki's Terms of Service
Revisions
- Requirement changes are free before the sketch is finished.- After the sketch phase, any changes will require an additional 5% fee based on the commission price, with a maximum of 3 changes per commission.- Once the final piece is delivered, no further edits will be made unless a mistake was made by Milkzuki.
Milkzuki's Terms of Service
Usage Rights
- Personal Use: Commissioners may use the artwork for personal purposes (profile pictures, printing for personal use, etc.).
- Commercial Use: If the artwork is intended for commercial purposes, an additional fee must be discussed and agreed upon.- Milkzuki retains all rights to the artwork, including the right to display it in portfolios, galleries, or promotional materials unless otherwise agreed upon.- The commissioner may not claim the artwork as their own, resell it, or use it for AI training or NFTs.
Milkzuki's Terms of Service
Cancellations & Blacklisting
- Milkzuki reserves the right to cancel a commission at any time due to inappropriate behavior, harassment, or failure to comply with these terms.- Any chargebacks or disputes will result in immediate blacklisting from future commissions.
Game Developer / Game Designer / UI/UX Designer
Milkzuki's Terms of Service
Welcome to Milkzuki's game development service. By collaborating with Milkzuki, clients agree to the terms and conditions outlined in this document. The purpose of this ToS is to ensure clarity and transparency between both parties throughout the development process.
Milkzuki's Terms of Service
Collaboration Terms
- Clients must be 18 years or older and have a basic understanding of how a game development project operates.- Game development projects are large-scale and require significant time and resources. As a result, costs will not be low, so clients should carefully consider their decision before committing to collaboration.- Clients must provide a detailed and well-structured Game Design Document (GDD) to ensure smooth and efficient collaboration.
Milkzuki's Terms of Service
Collaboration Process
- The timeline for a game development project is typically measured in months, with larger projects potentially extending beyond three months. The development process consists of three main phases: Design - Development - Testing.1. Design Phase- Both parties will hold meetings to discuss project details, development plans, and costs.
This phase typically lasts 3 to 5 days.- Once everything is agreed upon, the project will officially begin, and the client will be granted access to the project’s GitHub repository.2. Development Phase- Milkzuki will continuously update the project according to the agreed workflow, milestones, and deadlines.- Progress will be tracked through GitHub commits, allowing clients to monitor the development process easily.- Both parties will hold small review meetings to discuss specific details and address any project-related concerns.- If a milestone completion is delayed, Milkzuki will take full responsibility and offer a discount on the project.3. Testing Phase- Both parties will conduct game testing, focusing on two main objectives:+ Gameplay feel assessment – ensuring the game functions as intended and delivers the expected experience.+ Bug detection and fixes – identifying and resolving any remaining technical issues.- Since testing may reveal unexpected bugs that require fixing, this phase typically lasts about an additional week to ensure the game is polished before project completion.
Milkzuki's Terms of Service
Payment Methods
Clients can choose one of the two payment methods below:1. Milestone-based Payment- After completing each milestone, the client must make the full payment for that phase before receiving updates and progressing to the next stage.- If the client delays payment for too long, the project may be put on hold to avoid wasting time for both parties.2. One-time Full Payment- Before starting the project, a deposit will be required. The deposit amount can be negotiated based on the project's scope.
- Before the final steps of the project are completed and delivered, the client must pay the remaining balance in full. If payment is delayed, the client will lose access to the project's GitHub repository.
Milkzuki's Terms of Service
Intellectual Property Rights
- All products developed by Milkzuki will be jointly owned by both parties.- Clients have full rights to continue developing the project, assign it to a third party for updates, or publish the game on various platforms, but must provide proper credit to Milkzuki.- If clients wish to integrate third-party assets or plugins, they must clearly specify the ownership rights of those assets and provide proper credit as required.
Milkzuki's Terms of Service
Liability Limitations
- Milkzuki is responsible for any bugs or failure to meet the agreed-upon standards.- Milkzuki will provide testing and quality assurance to ensure the best product quality.- If the client modifies the source code or shares it with a third party, Milkzuki will be responsible to provide explanations on how the product works and how to use it. However, Milkzuki will not be responsible for any issues caused by third-party modifications.
Milkzuki's Terms of Service
Terms of Changes
- Once the project has been finalized, the client cannot change the core features and systems.- However, the client may request minor adjustments, add or remove features that have not yet been implemented, but these changes require Milkzuki’s approval. Since game systems are tightly interconnected, major changes could impact the entire project and cannot be made arbitrarily.- If project details are modified, the payment fee may be adjusted depending on the complexity of the changes.
Game Developer / Game Designer / UI/UX Designer
Milkzuki's Terms of Service
Chào mừng bạn đến với dịch vụ phát triển game của Milkzuki. Bằng việc hợp tác với Milkzuki, khách hàng đồng ý với các điều khoản và điều kiện được nêu ra trong tài liệu này. Mục đích của ToS này là đảm bảo sự rõ ràng và minh bạch giữa cả hai bên trong suốt quá trình phát triển dự án.
Milkzuki's Terms of Service
Điều Kiện Hợp Tác
- Khách hàng cần trên 18 tuổi và có hiểu biết cơ bản về quy trình phát triển một dự án game.- Các dự án game thường có quy mô lớn, yêu cầu nhiều thời gian và nguồn lực để hoàn thành. Do đó, chi phí phát triển sẽ không nhỏ, khách hàng cần cân nhắc kỹ lưỡng trước khi quyết định hợp tác.- Khách hàng cần chuẩn bị Game Design Document (GDD) chi tiết và rõ ràng để đảm bảo quá trình hợp tác diễn ra thuận lợi và hiệu quả.- Khi đã quyết định hợp tác (sau khi vào Giai Đoạn Phát Triển), khách hàng không thể đơn phương hủy bỏ dự án nếu không có lý do chính đáng.
Milkzuki's Terms of Service
Quy Trình Hợp Tác
Thời gian thực hiện một dự án game thường tính theo tháng, với các dự án lớn có thể kéo dài trên 3 tháng. Quy trình hợp tác sẽ bao gồm ba giai đoạn chính: Thiết Kế (Design) - Phát Triển (Development) - Kiểm Thử (Testing).1. Giai Đoạn Thiết Kế (Design Phase)- Hai bên sẽ có các buổi họp để thảo luận chi tiết về dự án, kế hoạch triển khai và chi phí.- Quá trình này thường kéo dài từ 3 đến 5 ngày.- Sau khi thống nhất toàn bộ nội dung, dự án sẽ chính thức bắt đầu và khách hàng sẽ được cấp quyền truy cập GitHub repository của dự án.2. Giai Đoạn Phát Triển (Development Phase)- Milkzuki sẽ cập nhật dự án liên tục theo milestone và deadline đã thỏa thuận.- Mọi tiến độ sẽ được theo dõi qua các commit trên GitHub, giúp khách hàng dễ dàng giám sát quá trình phát triển.- Trong quá trình này, hai bên sẽ có các buổi họp nhỏ để trao đổi, giải quyết các vấn đề liên quan đến dự án.- Nếu tiến độ hoàn thành của một milestone bị chậm trễ, Milkzuki sẽ chịu mọi trách nhiệm và hỗ trợ giảm giá cho dự án.3. Giai Đoạn Kiểm Thử (Testing Phase)- Cả hai bên sẽ tiến hành kiểm thử game với hai mục tiêu chính:+ Kiểm tra trải nghiệm chơi game (gameplay feel) – đảm bảo game vận hành đúng với thiết kế mong muốn.+ Phát hiện và sửa lỗi (bug fixes) – rà soát và khắc phục các vấn đề còn tồn đọng.- Giai đoạn này có thể phát sinh nhiều lỗi cần điều chỉnh, do đó thường kéo dài thêm khoảng một tuần để đảm bảo game hoàn thiện trước khi bàn giao.
Milkzuki's Terms of Service
Phương Thức Thanh Toán
- Khách hàng có thể lựa chọn một trong hai phương thức thanh toán sau:1. Thanh toán theo milestone- Sau khi hoàn thành từng milestone, khách hàng phải thanh toán đầy đủ khoản phí cho công đoạn đó trước khi nhận được bản cập nhật và tiến tới công đoạn tiếp theo.- Nếu khách hàng thanh toán chậm trễ hơn kế hoạch quá lâu, dự án có thể bị dừng lại để tránh làm mất thời gian của cả hai.2. Thanh toán một lượt cho toàn bộ dự án- Trước khi bắt đầu một dự án, một khoản đặt cọc (deposit) sẽ được yêu cầu, số tiền đặt cọc có thể thương lượng theo từng dự án.- Sau đó trước khi hoàn thành các bước cuối cùng của dự án và bàn giao, khách hàng sẽ cần phải thanh toán đầy đủ số tiền còn thiếu. Nếu chậm trễ, khách hàng sẽ mất quyền truy cập đến repository GitHub của dự án.
Milkzuki's Terms of Service
Quyền Sở Hữu Trí Tuệ
- Tất cả sản phẩm do Milkzuki phát triển sẽ thuộc quyền sở hữu chung của cả hai bên.- Khách hàng có toàn quyền tiếp tục phát triển dự án, giao cho bên thứ ba update hoặc phát hành game trên các nền tảng khác nhau, nhưng phải credit đầy đủ Milkzuki.- Nếu khách hàng muốn tích hợp sản phẩm, plugin của bên thứ ba, cần cung cấp rõ ràng về quyền sở hữu của bên đó và credit đầy đủ theo yêu cầu.
Milkzuki's Terms of Service
Giới Hạn Trách Nhiệm
- Milkzuki cam kết chịu trách nhiệm nếu sản phẩm gặp lỗi hoặc không đạt tiêu chuẩn đã thống nhất.- Milkzuki sẽ hỗ trợ kiểm tra và thử nghiệm (testing) để đảm bảo chất lượng sản phẩm tốt nhất.- Nếu khách hàng chỉnh sửa source code hoặc gửi cho bên thứ ba, Milkzuki vẫn hỗ trợ giải thích cách hoạt động của sản phẩm và cách sử dụng. Tuy nhiên, Milkzuki sẽ không chịu trách nhiệm nếu sản phẩm bị lỗi do tác động từ bên thứ ba.
Milkzuki's Terms of Service
Điều Khoản Thay Đổi
- Sau khi đã thống nhất dự án, khách hàng không thể thay đổi các chức năng và hệ thống cốt lõi.- Tuy nhiên, khách hàng có thể đề xuất thay đổi chi tiết nhỏ, thêm hoặc lược bỏ tính năng chưa thực hiện, nhưng cần có sự chấp thuận của Milkzuki. Vì hệ thống game có sự liên kết chặt chẽ, các thay đổi lớn có thể ảnh hưởng đến toàn bộ dự án và không thể tùy tiện thêm/bớt.- Khi thay đổi các chi tiết của dự án, phí thanh toán có thể bị ảnh hưởng tùy vào độ phức tạp của việc thay đổi.